Full opinion text
OPINION BROOKSHIRE, Justice. In March of 1988, Excavators & Constructors, Inc., (Excavators) filed suit against The City of Beaumont (City), Southwestern Bell Telephone Company (Bell), Gulf States Utilities, Inc. (GSU), Fittz & Shipman, Inc. (Fittz), and Liberty T.V. Cable, Inc. (Cable), for inefficiency and delay damages allegedly suffered by Excavators in the performance of a contract it had entered into with the City. Excavators settled with several of the entities prior to trial. Trial was had before a jury, and the jury found in favor of Excavators as against the City and Bell. Judgment was entered in favor of Excavators and it ordered the City to pay Excavators’ damages and also ordered Bell to partially indemnify the City under Ordinance No. 85-50. From that judgment this appeal ensued. The Basic Contract and its Provision for 220 Working Days and 240 Working Days for Final Completion Excavators and City agreed to a written contract on April 8, 1986, for nearly one million dollars to be paid and awarded to Excavators; Excavators was to provide street widening and other improvements to Highland Avenue, a street in the City. The widening and the improvements were to be substantially completed within 220 working days and finally completed within 21*0 working days. On April 8, 1986, Bell was not a party to the contract — it never was a signatory to Excavators’ contract. Bell had no contractual relation with Excavators and the telephone company was not advised that the contract had been actually awarded and executed until Bell received a notice in April of a certain preconstruction meeting (the precon-struction meeting). Query: Were the 220 working days available and salutary to the City? Query: Could not the City look to the 220 days in scheduling the City’s work? From the wording of the contract we think the answer is yes to each query. Nothing in the basic contract authorizes Excavators to accelerate the work on the project. The record reflects that Excavators completed its contract on the project within the allotted days. Excavators was assessed no penalty or other types of damages for untimely completion. The evidence clearly shows that Excavators made a 16.7 percent profit on the project, being about $168,000. Bell’s contentions are that Excavators finished the project within the contractually allotted time and made the profit that it intended to make. It was demonstrated that no loss or opportunity to bid or perform other work on any other contract existed. Excavators lost no other work. Excavators’ Position and Contentions vis-a-vis Bell Excavators brought a legal proceeding alleging that it was delayed in the performance of its excavation and improvement work by Bell’s delay in relocating its telephone poles. Excavators alleged it suffered damage as a result of the resequencing by Bell. Excavators claimed it suffered inefficiencies due to Bell’s delays in resequencing work. These inefficiencies were caused because Excavators contended it had to relocate and reassign its own equipment and its crews of working men. Excavators claimed damages for equipment rental charges and labor costs. These costs generally and very substantially occurred within six months from and after the preconstruction meeting. The Thomason Enterprises Question Excavators contended-for increased costs were associated with certain alleged inefficiencies which were caused in this case by Excavators■ own workmen and own working crews that were performing work that Excavators had previously subcontracted out to Thomason Enterprises (Thomason work). Relevant to this matter Excavators claimed that because of the delays forced upon it in its contract work, it was necessary to have its own employees perform the Thomason work so that Excavators would not have to lay off its employees and thereby allegedly run a risk that their own employees would be hired by another contracting firm. Nevertheless, Excavators affirmatively claimed that its own crew did not perform this previously subcontracted work as efficiently as Thomason would have and that such inefficiencies damaged Excavators in the alleged amount of about $102,785. The Thomason work issue resulted from the sole decision of Excavators. Not only did Excavators increase its cost and its alleged damages, it failed to mitigate its costs and damages. Thus, Excavators damaged Excavators. Evidence coming from a superintendent for Thomason showed that Excavators chose to perform the Thomason work simply because it was high profit work and that Excavators performed the work as efficiently as Thomason could have. Furthermore, this superintendent testified that Excavators often performed Thomason work when profitable to do so. The City of Beaumont’s Point of Error No. 1 and Reply Point of Excavators The City’s point number one contends that the trial court erred in overruling the City’s motion for judgment non obstante veredicto as the “no damage for delay” clause, contained in the basic construction contract between the City and Excavators, precluded recovery for delays or inefficiency damages. Excavators Duty and Responsibility to Inspect the Work Site The construction contract itself provided that the contractor would inspect the route of the construction during the bidding period and check that location for utilities and a possibility of any conflicts and problems as well as the addition of new utilities. Whenever any existing utilities presented obstructions to the work, then the contractor (Excavators) would notify the professional engineer on the job. When necessary to move any services, poles, guywires, pipelines or other obstructions, Excavators had the initial duty to make the necessary arrangements with the owners and operators of the utilities. We conclude the language of the contract and this duty put the contractor on notice that all of the changes involved would have to be made during the progress of the work— since Excavators insisted upon beginning the work immediately. Hence, Excavators should have known that there would be delays. And clearly, the construction contract provides that the owner (City) will not be liable for damage on account of delays due to changes made by the owner-operator of the utility involved which hindered progress of the work. Nor will the owner be liable for costs incurred by the contractor due to relocating utility service poles, services, and appurtenances. The “No Damage for Delay” Clause The term “owner” or “owner-operator” in the contract means the City, but the broad language used as to the owner-operator of utility poles would evidently refer to other utility owners and operators. Hence, certain issues are of paramount importance in this appeal. One, does the “no damage for delay” clause become implicated and viable under this record? Two, does the “no damage for delay” clause preclude Excavators (or rather recovery by Excavators) for loss of any inefficiency or delay damages? As usually construed, the so-called “no damage for delay” clause essentially denies the contractor the right to recover damages for delays of others in the performance of a construction contract. See, Maurice T. Brunner, Annotation, Validity and Construction of “No Damage” Clause with Respect to Delay in Building or Construction Contract, 74 A.L.R.3rd 187, 197-200 (1976). In Texas, similar provisions in construction contracts have been given effect by the courts. See City of Houston v. R.F. Ball Const. Co., Inc., 570 S.W.2d 75, 77 (Tex.Civ.App.—Houston [14th Dist.] 1978, writ ref'd n.r.e.). The wording of the clause makes obvious its purpose and intent which is to exculpate the City from liability for damages due to any delay from: (1) “changes made by the owner-operator of the utility which hinder the progress of work”, or (2) “incurred in relocating utility services, poles, services, and appurtenances.” It is not disputed that the contract between Excavators and City contains a valid no damage clause. In fact, Excavators put that contract in its entirety into evidence. The crucial question is whether the clause applies in such a manner as to defeat Excavators’ recovery of delay or loss of efficiency damages. There is a practical and pragmatic reason for “no damage for delay” clauses to be incorporated in such construction contracts. In this ease and under this record, the parties actually had knowledge and foresaw the possibilities of delays. The language of the contract itself stated: “It is contemplated that the removal of existing utilities in the construction area will be accomplished during the work of this contract.” It is obvious that the parties to the contract and especially Excavators actually contemplated delays under the contract since the work was to be done under the existing circumstances. Again, Excavators elected to start work at once, thereby breaching a scope of the work provision. The record reflects that Excavators had plenty of time and ample opportunity (at bidding time) to go to the area on Highland Avenue to inspect and perform a full reconnoiter of the proposed job area. In fact, the contract required Excavators to inspect the route and area of construction during the bidding period and to check the location of utilities; the possibilities of any conflicts, problems, and obstructions. Indeed, certain utilities had been relocated by the City during the work on a previous contract and a prior job that was performed by Excavators at a different site. Reply point number one and the City’s point number one argue and challenge this issue of “no damage for delay.” City contends that the very language of the contract simply disallows damages for delays or damages for inefficiencies caused by owners or operators of utilities. Excavators refutes this and counters by arguing that the damages for delays do not apply to damages that were allegedly sustained by Excavators in this case. Excavators argues that: (1) the no damage clause simply does not apply to Excavators here because this clause applies only to underground work and construction; and (2) the contract provides for damages for work delayed or hindered by the City if the Excavators suffered actual damages and if the contractee, that is, the City, was responsible for the cost caused by the delays. Bell’s Point of Error No. 1 and the No Legal Duty Defense Bell takes the adamant, uncompromising position that it (Bell) owed and owes no legal duty to Excavators. Bell maintains that it and Excavators were and are total, legal strangers. Bell claims that no duty whatsoever existed that was owed by Bell to Excavators. The record is clear that there is a total absence of any contract between Bell and Excavators. Hence, there can be no duty arising out of a ordinary contract. Bell argues that no common-law duty exists and no common-law duty is imposed upon it. Furthermore, Bell argues that the question of duty is strictly a question of law for the trial court or the appellate court to decide. See and compare Fort Bend County Drainage D. v. Sbrusch, 818 S.W.2d 392 (Tex.1991); Greater Houston Transp. Co. v. Phillips, 801 S.W.2d 523 (Tex.1990). Bell maintains that in determining the legal question of duty it becomes necessary that the trial court and this intermediate Court discern and define some definite relationship between the parties which is of such a character and quality that social policy justifies the imposition of a duty. The determination of a social policy which justifies the creation of a duty is not an easy exercise. See and compare William W. Kilgarlin & Sandra Sterba-Boatwright, The Recent Evolution of Duty in Texas, 28 S.Tex.L.Rev. 241 (1986). Bell insists that in an analysis of social policy and the related duty, a court must consider a number of interrelated, intermingled, and interdependent factors. These factors include the risk involved, foreseeability, the likelihood or probability of injury or damages. All of these are to be weighed against the social utility of the actor’s conduct, the magnitude of the burden of guarding against the injury, and the consequences of placing the burden upon an actor-defendant. See and compare Greater Houston Transp. Co. v. Phillips, supra, 801 S.W.2d at 525. Foreseeability has been characterized as the foremost and dominant consideration— the principle factor. See El Chico Corp. v. Poole, 732 S.W.2d 306, 311 (Tex.1987). Bell argues somewhat persuasively that it had no contract and no special relationship with Excavators; and hence, no duty to relocate its utilities in the road-widening project within a predetermined timing and sequencing schedule orchestrated by and for the convenience of Excavators. Bell places important reliance on Fort Bend County Drainage D. v. Sbrusch, supra, wherein Bell contends that the Texas Supreme Court was presented with a closely similar fact situation and scenario and wherein the High Court declined to impose a duty. Bell analyzes the Fort Bend County Drainage case as one in which the district had entered into an easement contract with the owner of a certain bridge. The bridge later collapsed causing injury to a third party. See and compare Southwestern Bell v. John Carlo Texas, 843 S.W.2d 470 (Tex.1992). The Policy Question of Creating and Imposing a Duty on Bell Southwestern Bell throws down its gauntlet to us in this fashion: If this court affirms the trial court’s Judgment, it will condone a legal act having no basis in the law, to wit, it will artificially carve out of this factual scenario a duty, unique to Southwestern Bell and other utilities companies, to insure against all unforeseen harm to third-party strangers. No other court has chosen to so cavalierly disrupt the delicate balancing of critical factors: the overriding social and economic needs of those with whom Southwestern Bell has a contractual and/or a special relationships, i.e., its customers and the public, balanced against the singular interests of a stranger. Accordingly, this court [the Ninth Court] must correct the egregious wrong perpetrated by the trial court, embrace the concept of stare decisis, and render that Southwestern Bell, as a matter of law, owed no legal duty to Excavators, a legal stranger, (emphasis theirs) In sum, Bell argues that it owed a legal duty solely and alone to the public, its customers, and to the City of Beaumont. No other duty existed. It is correct (as is contended by Bell) that there was no privity of contract or no direct, contractual relationship between Bell and Excavators. The formal contract made the basis of this litigation existed between Excavators and the City and no other party. That contract governed this street-widening project. Bell concedes that it did have a relationship with the City but argues that there were no contract terms or provisions or any other duties or obligations whereby Bell agreed to relocate its facilities in the time frame and sequence that was orchestrated by Excavators. We agree. Bell refers to a black-letter, axiomatic rule that a contract between other parties cannot create an obligation or duty on a non-contracting party, which non-contracting party was a stranger to the basic, underlying construction contract. See Bemarct-Johnson v. Continental Constructors, 630 S.W.2d 365 (Tex.App. — Austin 1982, writ refd n.r.e.). Bell argues that since there was no contractual duty, the courts must invent and conjure up and discover some other type of legal duty that would force Bell to relocate its facilities for the convenience and heightened profits of Excavators despite a potential detriment or real detriment to Bell and in turn to Bell’s telephone customers. Bell argues our Court would have to ordain a new and novel duty. See and compare El Chico Corp., supra. Bell, in essence, denies any such reasonable foreseeability of any risk of harm. We agree that Bell could not have reasonably foreseen a risk of harm at the time of the utterances or “iffy” future predictions made at the preconstruction meeting. We do not think that Bell’s representative, Scott Dillard, spoke in a negligent or deceit-fol or fraudulent or misleading manner at the preconstruction meeting — more on this issue below. Dillard did not negligently misrepresent future events. Bell argues, in addition, that it could not anticipate that Excavators would rely upon the timing or the sequencing utterances made by Bell at the preconstruction meeting. We agree. These utterances dealt with future actions which were contingent on weather, rain, and the performance of several third parties. Excavators was in quite a hurry to get out on the job and get started. The record reflects that Excavators stated unequivocally that it could have started the work a month prior to the preconstruction meeting. Bell sums up its argument along these lines: that for this intermediate court to impose a duty where there is no contractual relationship and no common-law theory and no statutory foundation and no familial relationship, then such duty would create an undue, unreasonable and oppressive burden mandating and requiring Bell to focus all of its energies on a contractor’s road-widening project so that it could make its bid profit and much more, while simultaneously depriving Bell’s telephone customers and the public of their legal rights. Admittedly, the arguments and rationales advanced by Bell are appealing pertaining to “no legal duty”. The City makes the notable contention that the “no damage for delay” clause is a complete defense to Excavators’ suit. The Record and the Applicability Thereunder of the “No Damage for Delay” Clause Both parties, the City and Excavators cite the clause contained in Item 600.07 of the contract. This clause has been and will continue to be referred to ás the “no damage” clause. Excavators insists that this “no damage” clause applies only to underground construction and underground work. This clause it says is not involved in this case. We disagree. The record proves otherwise. Under the heading of “Governing Specifications and Special Provisions”, there is an Item 600 entitled “Specifications for Underground Construction of Water and Sewer Pipes.” Item 600.01 describes underground constructions of water and sewer pipes. It, in relevant part, includes preparation of site, clearing, grubbing, excavation, street surface removal, boring, tunneling, dewatering, laying and joining pipe, bedding, back-filling, installation of fittings and manholes, testing and cleaning up of the site and other work. This Item 600 is not to be mistaken with (but makes specific reference to) Item 121 dealing with underground pipe construction which also deals with the street construction specifications of the City. In another part of the basic contract there is a section entitled “General Conditions”. Under this section, Article 4 sets out the availability of lands, physical conditions and reference points. Article 4 mandates that the City shall furnish the lands upon which the work is to be performed, rights-of-way and easements for access thereto and other lands which are designated for the use of contractor, being Excavators. Thus, there exists no such duty on Bell. Query: If the “no damage” clause did not apply to this project why was it in the basic contract; why did the plaintiff introduce the entire contract into evidence and how are the various references to underground construction explained? In other words, if the work done by Excavators strictly had nothing to do with any underground construction, why was this clause put into the basic contract which was agreed to by Excavators and the City? Such an important part of the contract, that is, the “no damage” clause, was obviously within the contemplation of the parties and there logically were intentions on the part of the parties to recognize it as an integral part of the basic contract. Important work done by Excavators was underground construction. The language spelled out in Item 600.01 defined underground construction. We think various clauses, phrases, provisions, and paragraphs of the contract are ambiguous; and if not ambiguous, they are inconsistent with each other. But the record reflects that under the contract the “no damage” clause stated that the owner (City) will not be liable for damages on account of delays due to changes made by the owner-operator (City). This clause applies to underground construction, but not exclusively to underground construction. Importantly, the underground construction, under this record, caused delays in the surface work. Damagewise, these delays were intertwined and intermingled. The delays caused by underground construction were not separable from the other delays. Certainly, Excavators’ expert on damages did not separate them. Thus, the “no damage” clause applies in this case. There is an additional, independent clause in the basic contract providing this: “nor will the OWNER [City] be liable for cost [sic] incurred in relocating utilities service poles, services and appurtenances.” This independent clause absolves the owner of utilities from liability of costs and damages occurring in relocating utilities and service poles. Moreover, Item 600.01 is harmonious and is to be read with Item 600.07, making doubly applicable the “no damage” clause. Excavators takes the position that the “no damage” clause of the basic contract simply does not apply to it but, this clause does not make such a limitation. Excavators further argues that the “no damage” clause is applicable only to underground construction and that its road work was not underground construction. But, the point that Excavators misses is that if underground construction as defined causes delays, inefficiencies, or hinders the surface work, then the owner or operator of utilities simply is not liable for such damages. Excavators has failed to prove a separation of the resulting confluent damages. The contract had an overall performance bond in the amount of $973,701.50. There were two bonds in the record, one for performance and one for payment, both of which were in identical amounts. The scope of the work clearly includes storm sewers and water line improvements. The scope of the work refers to storm sewer improvements. These improvements consist of extending inlet leads and building new inlets and even the construction of a new storm sewer system. Storm sewers are underground construction. The water line improvements consisted of replacing a six-inch, cast iron water line with a larger, eight-inch, asbestos cement water line. This eight-inch line was underground. Excavators fails to observe that when necessary to move any services, poles, guylines, pipelines, or other obstructions, the contractor was obligated to make the necessary arrangements with the owner-operator of the utilities. The general conditions of the contract specifically provide that the contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of the construction, including notice to the utilities of any problems. The contractor had the duty to make adequate planning and preparation before excavations started. Item 600.02 entitled “Sequence of Work” so mandates. Testimony of William Schwartzkopf, Excavators’ Expert, on Damages The plaintiff, Excavators, offered an expert, one William Schwartzkopf. He testified that Excavators total damages amounted to $230,721. This exact amount was awarded by the jury. This total sum resulted from all the delays and all inefficiencies by all participants and parties on the job. Schwartzkopf freely admitted upon cross examination that he could not give the jury a total number of days that Excavators had been delayed. This expert also admitted that he had not done a causation study. He gave no opinion as to causation as to what delay, if any, caused what damage. He gave no opinion as to what party or defendant caused what damage. He conducted no study as to an allocation of the damages between the City and Bell. He gave no allocation of the damages between the numerous parties. The plaintiff had the burden of proving that the delays and hindrances (and the events connected therewith) that were sued upon actually caused the plaintiffs money damages. That burden is an essential element of Excavators cause of action and the amount of resulting damages must be shown. The causal nexus as well as the amount of damages must be demonstrated by competent evidence. In Morgan v. Compugraphic Corp., 675 S.W.2d 729, 732 (Tex.1984), the Court held: Whether the event sued upon caused any injuries to the plaintiff is another matter entirely. The causal nexus between the event sued upon and the plaintiffs injuries is strictly referable to the damages portion of the plaintiffs cause of action. Even if the defendant’s liability has been established, proof of this causal nexus is necessary to ascertain the amount of damages to which the plaintiff is entitled.... Proving that the event sued upon caused the plaintiffs alleged injuries is part and parcel of proving the amount of damages to which the plaintiff is entitled. The causal nexus between the event sued upon and the plaintiffs injuries must be shown by competent evidence. Furthermore, the plaintiff in an alleged breach of a construction contract must show the nature and extent of the various delays for which damages are claimed. Plaintiff must show and connect these delays and hindrances to some act of omission or commission or breach on the individual defendant’s part. The damages, if any, caused by each defendant must be proved. See Wunderlich Contracting Company v. United States, 351 F.2d 956, 173 Ct.Cl. 180 (1965). Yet this leniency as to the actual mechanics of computation does not relieve the contractor of his essential burden of establishing the fundamental facts of liability, causation, and resultant injury, [citations omitted] It was plaintiffs’ obligation in the ease at bar to prove with reasonable certainty the extent of unreasonable delay which resulted from defendant’s actions and to provide a basis for making a reasonably correct approximation of the damages which arose therefrom, [citations omitted] Broad generalities and inferences to the effect that defendants must have caused some delay and damage because the contract took 318 days longer to complete than anticipated are not sufficient, (emphasis theirs) Id. 351 F.2d at 968. Excavators failed to prove such necessary approximations. The burden rests upon the contractor to establish by competent evidence the duration of the delay, the fact of such delay, and that there was no greater fault of the contractor involved, and that there was a causal relationship between such delay and the necessity and reasonableness of additional actual cost. J.D. Hedin Construction Company v. United States, 347 F.2d 235, 171 Ct.Cl. 70 (1965), held: It is well settled that the government is relieved of liability irrespective of its faulty specifications, where the actual delays were occasioned by factors outside the government’s control. It is well settled that where delays are occasioned by factors beyond the control of the contractor or the government, a contractor cannot recover damages from the government for the delays, nor can the government properly assess liquidated damages against the contractor. This holding and its rationale are uniquely applicable to this appeal. We must stress the fact that Schwartzkopf admitted that he could have formulated an opinion as to causation; and he could have formed an opinion allocating the damages against each individual defendant. He unequivocally stated that he had not been asked to make the necessary calculations. Excavators had not authorized this necessary work study. Schwartzkopf had been contacted about a year before trial to become engaged in this litigation by Excavators. He stated that his opinion revolved around analyzing the actual cost of performance. As an expert, he had visited the jobsite. This visit was after the construction had been completed. The construction had been completed more than three years when Schwartzkopf made his first visual inspection of the site. In his opinion, Excavators had been faced with both inefficiency problems and delay problems from other factors and entities not attributable to the City or Bell. This witness had prepared an analysis or summary of his opinion of the damages in January of the year of trial, being 1991. One of the first elements or items of additional cost was what was described as flatwork. “Flatwork” was the term for the concrete driveways and pavements. This work had originally been subcontracted to Thomason, but was later done by Excavators itself at an additional cost to Excavators of $102,785. The expert stated that at first this sounded like a very poor business decision, but this was done to keep the work crew together. Query: Was this an element of damages against the City and Bell? We think not. The appellee’s position on this point (in determining to directly perform previously subcontracted work) was that it was being told that the telephone company was working on getting the poles out of the way and that the other entities were clearing the area ahead of Excavators. The expert stated that Excavators had made a prudent business decision. The expert then described another item as being additional equipment cost of $65,374. The expert then included a third item, an additional payment to Thomason. We perceive that the record reflects that this payment to Thomason was an additional sum of money over and above Thomason’s contract price to attempt to compensate Thoma-son. Query: Was this to be charged against the City and Bell? The next item of additional indirect cost amounted to in excess of $31,800. This was based on the expert’s testimony that the project could have been finished by September 30, 1986, but was not finished until later. Therefore, if the job had been completed by the end of September of ’86, the Excavators could have moved on to other projects and these so-called indirect costs could have been charged to the other projects. However, no other new, available projects were shown by Excavators. The climacteric of this expert’s testimony in the record is: Q. And you’ve come up with a final number for delay or disruption damages in this case of how much? A. $230,721. The trial judgment was entered in favor of Excavators against the City in the amount of $230,721. This was the exact amount of all the delay and inefficiency damages as testified to by Schwartzkopf to the very dollar and to the very cent. This was also the jury’s finding. Against the city was an additional pre-judgment interest award of $125,494.57. Additionally, Excavators concedes that it experienced certain excavation delays from causes other than those alleged in the law suit. It referred to missing engineering layouts, rain, hurricane, shutdowns, and underground utilities including, inter alia, gas and water lines and certain underground conduits. It is abundantly clear’ and firmly established that Schwartzkopfs estimate of damages truly represented the total amount of all factors and by all actors and entities on the job. The jury answered precisely the estimate and amount testified to by Schwartz-kopf; hence, the jury answer levels damages against the City and Bell, some of which had to have been correctly attributable to Cable, GSU, Entex, and other subcontractors on the project as well as the professional engineers. Hence, the figure of $230,721 obviously could not be correct; it includes confluent, synchronous damages. Sehwartzkopf testified: Q. Well, let’s just move to — finally to the delay portion. And is your figure — are your figures intended to represent the total delay — inefficiency damages caused by any delay to excavation, including delays by TCI or Liberty Cable, GSU, Entex, or anybody else out there? A. They’re intended to represent the total delay by other than normal causes. I mean, clearly on a day-to-day basis, if you get a rainstorm, that’s a delay; but that’s an expected and estimated in the job delay. The delay from what I call third parties, the people you mentioned, that’s the— Q. Yeah. Your figure’s not for damages caused by the delays alleged or charged to the City of Beaumont particularly over water meters? A. To the extent those are normal delays and I — that’s correct. Q. This calculation is not intended to represent damages which you consider attributable to the presence of Southwestern Bell poles? A. Well, a significant part of this delay, from my reading — and I didn’t do a causation analysis. But a significant part of it does appear to be attributable to Southwestern Bell poles. Q. But you have not done a causation study and no allocation? A. I have not done an allocation. That’s just from reading the jobsite diary — not the diary, the daily reports. They appear to be a significant cause, those poles being there. Q. You’re saying that’s true of GSU poles; isn’t that correct? A. I’d have to say I can’t differentiate between whose poles they were. It was poles generally. Thus, Sehwartzkopf included delays by GSU and damages caused by GSU as well as others. Again, the $230,721 damage figure encompasses all the delays and disruptions claims and damages attributable to “anybody ... out there”. This damage award was confiseatorily adjudged against the City and Bell. It is unfair; it emasculates due process; an orchideetomy has been performed on the law of. damages. Reversible error is proved. Sehwartzkopf testified that through July 31st of the trial, his total charges as an expert witness would be $12,580.34. In the absence of a contractual provision to the contrary, a contractor situated such as Excavators may be entitled to recover damages from a contractee home rule city, for losses due to delay, inefficiency and hindrance of the work; but the contractor must prove: (1) that its work was delayed or hindered; (2) that it suffered damages because of the delay and hindrance; and very importantly, (S) that the contractee was responsible for the act or omission which caused the delay, the inefficiency, or the hindrance. This Excavators has failed to do. The City would not be responsible for delays caused by third parties, or subcontractors, or other utilities owners or operators, or acts of nature, or acts of God; nor would Bell. The Causation Issue To undergird and buttress our opinion we note that the record shows from Excavators’ expert: Q. Okay. You personally can’t give us a total amount of days that Excavators & Constructors was delayed on this project? A. I wasn’t asked to do that as part of my analysis; so, no, I can’t do that. Q. You weren’t asked to give any opinions on causation in this case at all? A. No. (Emphasis added) Thus, Sehwartzkopf unequivocally stated that his opinion of damages was not based or allocated on causation as to the various original defendants and certainly not as to the City and Bell. We perceive Excavators had settled with several other defendants before trial. The settling defendants are not parties in this appeal. The expert testified that there was definitely some overlapping of the delay claims and the inefficiency claims. No productivity study had been done in this case, nor had this expert been asked to do a schedule analysis. The scheduling analysis was to have been furnished and distributed by Excavators; but Excavators failed to do so. Importantly, this expert was asked: Q. The analysis that you have here is based on an assumption that all of these delays were caused by utilities; is that correct? A. No, that’s not entirely correct. It’s based on the assumption that all of the delays are caused by persons other than Excavators & Constructors. Q. Okay. You haven’t segregated these various and sundry delay claims among the various companies involved out on the project? A. I have not been requested to do that, nor have I done that. (Emphasis added) “[D]elays are caused by persons other than Excavators & Constructors” definitely includes defendants, entities and factors other than the City and Bell. But the judgment provides that the City and Bell pay all damages — the total, concurrent, intermingled, coeval damages. This is error requiring reversal. At another point in his testimony the expert, Sehwartzkopf, unequivocally testified that his figures on damages represented the total delay and the total inefficiency damages and delay damages caused by any delay to the excavation, including delays by Cable, GSU, Entex, or anybody else out on the job. His damage figures definitely included, in the total damages for delay amount, damages caused by a number of entities other than the City and Bell. Again, the expert reiterated that he did not make a causation analysis and he had not made a study as to the allocation of damages. His answer was: “I have not done an allocation. That’s just from reading the job-site diary — not the diary, the daily reports.” This important testimony was reiterated time and again. We find again in the record, question: “Again, you’ve done no study of causation in this case?” Answer: “That’s correct. ” The record reflects: A. Well, I don’t do a causation delay analysis at all. I’m not quite sure what your question is but I didn’t do — I mean, I wasn’t asked to do a causation delay. I was asked to assume that delays — what the delays were and do a damage analysis accordingly. (Emphasis added) Hence, the answers of the expert could not have been inadvertent; they were repeated several times. Mr. Sehwartzkopf agreed that the job had been finished for about four years before he had first had a chance to even view the project site. Further, as we interpret the record there were included damage estimates made concerning the work taken back by Excavators from Thomason, a subcontractor. Extra labor costs were incurred by Excavators. In usurping Thomason’s work, Excavators wounded itself; it failed to mitigate damages. It must be noted that there is evidence of considerable probative evaluation that Excavators took over the Thomason work because the same would be highly profitable to Excavators; but Thomason had bid the work at a cheaper amount. The jury answered the damage issue at precisely the same total damage figure given by the expert, namely, $280,721. Hence, this figure was brought forward in the judgment against the City and Bell. It necessarily is incorrect, egregious, and requires a reversal of the judgment. The jury’s answer necessarily had to include some double damages or elements of damage or overlapping damages or wrongfully assessed damages against the City and Bell. The record proves that the underground construction interfered with the surface excavation work. Hence, Excavators was awarded damages and monies that were disallowed by the basic contract. We note that an important decretal paragraph of the judgment awards Excavators $230,721.00 against the City of Beaumont, plus interest on that sum from April 8, 1987, through October 18, 1991, the date of the judgment, the total amount of interest amounting to $125,494.57. Thus, this interest award is incorrect. Then this important decretal paragraph orders that this portion of the judgment against the City, together with all pre-judgment and post-judgment interest, shall be a joint and several judgment also against Bell. Thus, the joint and several judgment against Bell is contaminated, erroneous, and harmful. In addition, $173,040.75 was ordered to be received by Excavators from Bell, plus certain pre-judgment and post-judgment interest leveled against Bell. Since we have found harmful, reversible error in the initial amount of $230,721, the joint and several liability against Bell must necessarily be reversed. In a later and paramount decretal paragraph, the judgment decreed that the total amount of the trial judgment in favor of Excavators against the City to be $777,497.23 plus taxable court costs which figure excluded, of course, post-judgment interest and appellate attorneys’ fees. But this figure of $777,497.23 included the erroneous figure of $230,721. The paragraph contained an order that was based on the recovery theory of promissory estoppel. Excavators recovered against Bell $537,161.67 and this $537,161.67 amount was awarded jointly and severally against the City and Bell. The erroneous amount of $230,721 vitiates and pollutes the subsequent mathematical calculations. Then in a later decretal paragraph, the judgment recites that based on the pleadings of the parties, the evidence adduced at trial, and the jury’s verdict; the court had determined (pursuant to the terms of the franchise agreement between the City and Bell which was admitted into evidence) that the City is entitled to partial indemnity from Bell for a part of the judgment owed by the City to Excavators. Then the judgment recites that the City have and recover a judgment for indemnity against Bell for all amounts paid to Excavators pursuant to the judgment up to: (1) 75% of the $226,106.58 in delay or loss of efficiency damages suffered by Excavators for which the City is responsible, [the 75%] totalling $169,579.93; [Note: the harmful $230,721 — less some small credits given the City reducing $230,721 to $226,106.58 — is the basis of this erroneous calculation] (2) 75% of the pre-judgment interest of $122,984.68 on that sum amounting to $92,238.51; [This amount of interest is wrong] (3) 75% of the $296,450.00 in attorneys’ fees, professional fees and trial exhibit costs for which the City is responsible to Excavators totalling on this third element $222,337.50; (4) 75% of all the appellate attorneys’ fees for which the City becomes responsible to Excavators in the event of an appeal in this case; (5) 75% of all taxable court costs for which the City is responsible; and (6) post-judgment interest which accrues on all the sums set out above. We conclude the City is not indemnified from Bell for attorney’s fees, professional fees, and exhibit costs. Again, necessarily, the erroneous, invalid $230,721 is the basis of all the other large awards and for that reason the judgment against Bell must be reversed. Promissory Estoppel Under this record, we determine that promissory estoppel is not the basis for an affirmative cause of action leading to a recovery under the facts presented in this case. Restatement (Second) of CONTRACTS § 90 (1981) has generally dealt with the doctrine of promissory estoppel as being based on that type of promise which the promisor should reasonably expect to induce action or forbearance on the part of the promisee or a third person and which does induce such action or forbearance. Promissory estoppel becomes applicable if, but only if, injustice can be avoided only by the enforcement of the promise. But a promise must be made. We conclude that no promise was made; we conclude Excavators did not rely on Dillard’s utterances; and we so hold as a matter of law. Promissory estoppel in its basic requirements demands: (1) a promise, (2) foreseeability of reliance thereon by the promi-sor, and (3) substantial reliance by the prom-isee to his detriment. English v. Fischer, 660 S.W.2d 521, 524 (Tex.1983); Traco, Inc. v. Arrow Glass Co., Inc., 814 S.W.2d 186, 190 (Tex.App.—San Antonio 1991, writ denied). Excavators has failed in each of these requirements. Decisional precedent establishes a fourth and separate element or requirement to engage the doctrine of promissory estop-pel. That fourth and separate element is a definite finding that injustice can be avoided only by the enforcement of the promise. See Fretz Const. Co. v. Southern Nat. Bank, Etc., 600 S.W.2d 878 (Tex.Civ.App.— Houston [1st Dist.] 1980), rev’d and remanded on other grounds, 626 S.W.2d 478 (Tex.1982). Moreover, Excavators has failed to prove the correct measure of damages under promissory estoppel. In a guarded manner, we perceive, the Texas Supreme Court has refraining from overtly and affirmatively condoning approval of promissory estoppel in situations such as the one before us. The Supreme Court has written on this issue and stated that estoppel is defensive in nature and operates to prevent the loss of an existing right. It does not operate to create liability where it does not otherwise exist. Hruska v. First State Bank of Deanville, 747 S.W.2d 783 (Tex.1988). The alleged promises that were sought to be made actionable against Bell, we determine, occurred at the preconstruction meeting of April 17, 1986. The record reflects that when the parties met on April 17, 1986, a contract had already been signed between Excavators and the City. Excavators had by a prior, solemn contract committed itself to performing the project in 220 working days and finalizing the same in 240 working days with or without Bell’s alleged promise to do anything. Excavators did express its hope to complete the project within six months. Comments were made during the precon-struction meeting to the effect that Excavators had an on-going, binding commitment to the project and a commitment to complete the contract. Excavators said that it needed a work order right away on that very day and that it was even ready to start a month prior to the preconstruction meeting. Excavators explained that its employees had assembled their barricades and it could be out on the project area working by the following day. Excavators announced it was planning to work five or six days a week. In view of these statements, it is impossible to conceive how Bell could have reasonably foreseen Excavators’ alleged reliance on any utterances of Bell or on the doctrine of promissory estoppel or how Excavators could have relied upon any so-called negligent misrepresentation, if any, made by Bell. At this same meeting it was clearly shown that GSU still had a good deal of work to do in the future and the representative of Bell clearly warned and notified the attendees that Bell would be able to start its work as soon as GSU had completed its project. Furthermore, Bell’s representative merely stated that Bell was looking at probably four weeks on Bell’s part; but no starting date was given for Bell. At that time none could be given because Bell had to wait on other parties, including Cable and Gold Crest Electric Company, among other factors. The weather was one factor. In fact, the owner of Excavators explained that (depending on how many people Excavators decided to put on the job): “We don’t intend to drag our feet that’s for sure.” Excavators was in a big hurry. There was no reliance by Excavators on the phone company’s utterances. Furthermore, the phone company’s representative clearly explained that GSU had to complete its work and then Cable had to transfer everything (including all of its lines) and complete its work before the phone company could start. There simply was no promise in the sense of a legal promise that Excavators could rely upon. Bell’s representative explained that there were going to definitely be some problems with Entex. The representative of Excavators acknowledged that it would do storm sewer work which involved underground construction, implicating the “no damage for delay” clause. In fact, Excavators at the preconstruction meeting was noticed and warned that the phone company had an underground system and that a manhole was involved, demonstrating underground construction and work and this brought again into play the “no damage for delay” clause. This clause certainly applied to the owner-operator of the phone utility as to underground work. Furthermore, at the same meeting Excavators was specifically warned and noticed to the effect that Bell and Cable as well as other utilities were going to run into problems at the location of the school and possibly with property owners and also with some prehistoric oaks. Hence, Excavators knew that there were possibilities and even probabilities of delays. In fact, all the parties were warned concerning the property owners and concerning the prehistoric oaks. Interested citizens were very particular about these large, ancient oaks. These citizens desired to completely protect these beautiful trees adjoining a nostalgic high school. We conclude that the so-called alleged promises were merely utterances or some speculative ideas as to future events. No negligent misrepresentation occurred. During the April 17th discussion at a point — but not as a response or answer to any question or query posed by Excavators — Bell’s representative, Scott Dillard, stated that Bell was “looking at probably four weeks on our part” — “probably” is the operative word. Later in the same meeting, Earl Cooper, the superintendent and representative of Excavators, posed a question to the different utility representatives. The question in general was, “how long would Excavators be looking at everybody getting off the pole so that they could be moved.” In response to that question there was no definite or set time frame. Bell gave no response and made no promise as a response to the query. Bell maintains that it was speculative as to the timing of Bell’s instigation and completion of the relocation work. Moreover, Bell maintains that although making no promise or response after Earl Cooper’s statement that Excavators wanted to complete the project in about six months, Bell later went back to its drawing board and completely redrafted its plan to provide a mostly aerial relocation of its lines. Such aerial relocation would be quicker. Bell had originally planned for underground construction. Bell contends it accommodated Excavator’s schedule as readily and as reasonably as could be. Excavators never solicited a time and sequence commitment from Bell. Excavators did not contact Bell while Excavators was preparing its bid or entering into the contract with the City. We hold that the burden was on Excavators to prove that it was induced to act and did act in reliance upon the alleged promises by Bell. Excavators failed its burden. Excavators’ actions disproved any reliance. The doctrine of promissory estoppel is defensive in nature. We conclude that the doctrine of promissory estoppel is not available to Excavators. We hold that Excavators cannot recover lost profits or anticipated profits or increased profits under the doctrine of promissory estoppel under the record before us. The Doctrine of Negligent Misrepresentation By like reasoning, the theory of negligent misrepresentation does not entitle Excavators to lost profits or damages. See Restatement (Seoond) of ToRts, § 552B (1977). This provision mandates that the damages recoverable under the theory or cause of action known as negligent misrepresentation are only those damages which would necessarily be awarded to compensate the plaintiff-litigant for actual pecuniary losses he has suffered upon and because of his actual reliance upon the misrepresentations — but here there is no reliance — nor negligent misrepresentation. Under this doctrine of negligent misrepresentation, the defendant must supply known false information. Federal Land Bank v. Sloane, 825 S.W.2d 439 (Tex.1991). We find that Bell did not supply false information under this record. Dillard’s utterances were guesses as to future, unknown happenings; they were not information. Dillard did not knowingly lie about the future. Again, under this theory, we fail to see that Excavators demonstrated reliance by evidence of probative value. The Restatement provides that damages for this tort do not include the benefit of the plaintiffs contract with the defendant. Here again, however, there was no contract or privity of contract between Excavators and Bell. See Restatement (Second) of ToRts § 552B (1977). See also Restatement (Seoond) of Torts § 552, Comment a. Under this doctrine of negligent misrepresentation the Supreme Court wrote in Federal Land Bank, 825 S.W.2d at 443: “We decline to extend damages beyond those limits provided in Restatement section 552B.” The utterances had to do with future events. There were complicated problems with the future events. There were hindrances and delays inherent in the future events. Bell’s actions were dependent upon the actions of third, fourth, and fifth parties. From what has been discussed above, it appears that the element of justice must be established in order to truly invoke the doctrine of negligent misrepresentation or negligent representation. We think that injustice to Excavators has not been shown in this record. We find no evidence of negligent misrepresentation. Excavators made a handsome profit on the project. Indeed, we decide a very careful reading of the transcript of the preconstruction meeting demonstrates it was replete with warnings and admonishments by Bell to Excavators of Bell’s uncertainties of having to wait on the completion of the work of others, of no definite beginning date, and no definite ending date. We perceive that an essential element of the cause of action based on negligent misrepresentation is that the negligent misrepresentation had to contain the element of negligence at the time it was uttered. There is no evidence that what Bell’s representative uttered was done in a negligent manner. He was not clairvoyant; he was not a seer of the future. In fact, a very careful reading and analysis of the notes and verbatim transcription of the preconstruction meeting would show rather that the speaker uttered statements that were full of caution. Burden of Proof on Damages— Whose Burden? The amount of damages needs to be proven with reasonably certainty as to each defendant. This is the plaintiffs burden. The causation or causal connection between the event sued upon and the plaintiffs injuries or damages must be demonstrated by evidence of‘probative value. See and compare Morgan v. Compugraphic Corp., 675 S.W.2d 729 (Tex.1984). When dealing with a contract of construction, the plaintiff has the burden to show the nature and extent of the various alleged delays and the damages which are connected or caused by the delays on each defendant’s part. See and compare Wunderlich Contracting Company v. United States, 351 F.2d 956, 173 Ct.Cl. 180 (1965); see and compare J.D. Hedin Construction Company v. United States, 347 F.2d 235, 171 Ct.Cl. 70 (1965). No causation proof of probative value was presented. Proving the total of confluent, synchronous, coeval damages is wholly inadequate. Apportionment of Damages Furthermore, there was no apportionment of the damages between the two remaining defendants. Under established rules of damages as applied in Texas, when certain damages or injuries result from two or more different causes and one defendant is liable for some of the causes of the damages but not all; then in order that there be a proper award of damages, it becomes incumbent for the plaintiff to establish which portion of the damages resulted from the causes for which a particular defendant is liable. 28 TexJur. 3d, Damages, § 227 (1980); see and compare, Tucker Oil Co. v. Matthews, 119 S.W.2d 606 (Tex.Civ.App.— Fort Worth 1938, no writ); see also and compare Panhandle & S.F. Ry. Co. v. Wiggins, 161 S.W.2d 501 (Tex.Civ.App.—Amarillo 1942, writ ref'd w.o.m.). The Pleadings of Excavators Excavators’ causes of action against Bell encompassed negligence, negligent misrepresentation and promissory estoppel. Excavators alleged breaches of certain representations or promises allegedly made by Bell. Additionally, Excavators pleaded for attorney’s fees and interest and sued the City for its expert fees and also for its trial exhibits. In the latter part of April 1991, the City filed a cross-action against Bell for indemnities allegedly due the City pursuant to the City’s Gross Receipts Ordinance No. 85-50 — the franchise. This particular cross-action was to be tried separately as announced by the trial Bench. The jury responded to the questions and found in pertinent, relevant part that the City had failed to comply with its obligations to relocate the utilities and that Bell caused delay damages. Bell’s Position on Indemnity Under the Franchise Bell contended that before the entry of the final judgment at trial level, Excavators elected to recover against Bell solely under promissory estoppel, being the only theory affording recovery of attorney’s fees by plaintiff. We determine Excavators cannot recover attorney’s fees, experts’ fees, and its exhibit cost against Bell. Furthermore, Bell complained that in what it contended to be a surprise ruling (and without any notice or opportunity to present any evidence), the trial court entered a judgment in favor of the City against Bell under the indemnification theory. The indemnification part of the judgment ruled that the City was entitled to certain partial indemnities for the amount it was required to pay to Excavators. Later, in December of 1991, pursuant to a request of Bell, the trial court rendered findings of fact and conclusions of law dealing with the City’s indemnification claim against Bell. In January of 1992, certain supplemental findings of fact and conclusions of law were rendered. However, Bell's later objections and requests for either additional or amended findings of fact and conclusions of law were denied by the trial judge. Bell presents points of error contesting the judgment in favor of the City adverse to Bell, based on indemnification under Ordinance 85-50. Bell contends that prior to the trial of Excavators’ claims, the trial court determined to hear the indemnification cross-action against Bell at a later, separate time. Accordingly, the trial proceeded only on Excavators’ remaining theories against Bell, the City, and Fittz & Shipman, Inc. Fittz & Shipman was dismissed at the close of the evidence by the trial court. Bell’s Points of Error Two, Three, and Four — Challenging the Damages Awarded The record clearly reflects that the only measure of damages and the amount thereof proffered by Excavators was its so-called loss of efficiency and delay damages which resulted from multiple factors and resulted also from multiple actors and parties, including one subcontractor who was not a party. These elements of damages and amounts of damages were not restricted to Bell’s alleged nonperformance or the City’s alleged failure to relocate certain water meters and coordinate certain other utility relocations. Excavator’s expert gave testimony that his ultimate conclusion and bottom line figure was based on a total number of delays and inefficiency damages that were caused by actions of numerous entities and natural forces other than the City and Bell and that, furthermore, the damages suffered by Excavators included multiple factors and utilities other than water meters and poles. The record reflects (by Sehwartzkopf): Q. In this case you have not been requested to do a schedule analysis, have you? A. That’s correct. Q. And you haven’t done a schedule analysis? A. And I have not done one. Q. The analysis that you have here is based on an assumption that all of these delays were caused by utilities; is that correct? A. No, that’s not entirely correct. It’s based on the assumption that all of the delays are caused by persons other than Excavators & Constructors. Q. Okay. You haven’t segregated these various and sundry delay claims among the various companies involved out on the project? A. I have not been requested to do that, nor have I done that. Q. And you understand that it’s customary in the construction business for utilities, specifically those having aboveground poles, not to move their pole until everyone’s off of that pole? Isn’t that typical? A. To restate what I think you said, normally the owner of the pole won’t move that pole until all of the wires are off of the pole, no matter who they belong to. Q. And that’s the practice in the industry? A. Tha